THE PUNJAB PRIVATE HOUSING SCHEMES AND LAND SUB-

DIVISION RULES 2010

SOR(LG)38-2/2004-P

[13^th March, 2010]

CHAPTER I

INTRODUCTION

1. Short title, extent and commencement.— (1) These rules may be cited as the Punjab Private Housing Schemes and Land Sub-division Rules 2010.

(2) These shall come into force at once.

2. Definitions.— In these rules—

(i) “Authority” means a governing body of a development authority established under the law for the time being in force

(ii) “chamfer” means the flat surface made by cutting of sharp edge or corner of a plot to enhance the visibility at the turning point;

(iii) “company” means a company registered under the Companies Ordinance,

1984( XLVII of 1984);

(iv) “competent authority” means the authority competent to approve a private housing scheme, a farm housing scheme and land sub-division;

(v) “controlled area” means the area notified by a Development Authority as the

controlled area under section 18 of the Lahore Development Authority Act 1975 or under section 17 of the Development of Cities Act 1976;

(vi) “conversion charges” means the charges levied by a local government or Development Authority concerned for conversion of land use;

(vii) “cooperative society” means a society registered under the Cooperative

Societies Act, 1925(VII of 1925);

(viii) “Council” means a Zila Council, Town or Tehsil Council;

(ix) “developer” means a company or a cooperative society or a firm or an owner of land who intends to develop a scheme or who has developed a scheme after approval.

(x) “Development Authority” means a Development Authority established under

Lahore Development Authority Act, 1975(XXX of 1975) or under the Punjab Development of Cities Act, 1976(XIX of 1976);

(xi) “District Planning and Design Committee” means a District Planning and

Design Committee constituted by the Government under the Land Use

( Classification, Reclassification and Redevelopment) Rules 2009;

(xii) “educational institution” includes a school, college, university, research or training center, library or a madrassah;

(xiii) “farm house” means a dwelling place attached to a farm on a plot not less than four kanal;

(xiv) “Government” means the Government of the Punjab housed in the Local Government and Community Development Department;

(xv) “Horticulture” means the art or practice of garden cultivation, tree plantation, arranging of grass and flower beds;

(xvi) “Infrastructure” means the services including road network, water supply, drainage and sewerage system, telephone, gas, cable and power lines;

(xvii) “kanal” means a size of land equal to twenty marlas;

(xviii) “landscape plan” means a plan showing visible feature in an open space in a scheme such as walkway, green area, fountain, flower bed, grass and trees;

(xix) “land sub-division” means sub-division of a plot into two or more plots in an approved housing scheme or sub division of land into two or more plots in other areas;

(xx) “local government” means a City District Government, a District Government, a Town Municipal Administration, or Tehsil Municipal Administration;

(xxi) “low income group” means a person who has monthly income not exceedingRs. 15.0007-, duly authenticated by the concerned Union Nazim;

(xxii) “marla” means, a size of land equal to two hundred twenty five square feet in Lahore district and two hundred seventy two square feet in other districts of Punjab;

(xxiii) “major road” means a road having a right of way of eighty feet or above;

(xxiv) “master plan” means a land use plan of an area and includes a structure plan, an outline development plan, a spatial plan, peri-urban structure plan, integrated development plan and a metropolitan plan;

(xxv) “Ordinance” means the Punjab Local Government Ordinance 2001 (XIII of 2001) ;

(xxvi) “peri-urban area” means an area that spans the landscape between contiguous urban development and rural countryside with low population density and is predominantly being used for agricultural activity and is likely to be urbanized in the next twenty years;

(xxvii) “peri-urban structure plan” means a plan indicating the proposed road network and type of development in the peri-urban area in accordance with Land Use Rules 2009 ;

(xxviii) “property” means a plot or a building in a scheme;

(xxix) “public building” includes a dispensary, post office, police station, local government office, educational institution, hospital, clinic, mosque and fire station;

(xxx) “Land Use Rules 2009” means the Punjab Land Use (Classification,

Reclassification and Redevelopment) Rules 2009 notified by the Local Government

& Community Development Department and the Lahore Development Authority

Land Use (Classification, Reclassification and Redevelopment) Rules 2009 and the

Punjab Development Authorities Land Use (Classification, Reclassification and

Redevelopment) Rules 2009 notified by the Housing Urban Development and Public Health Engineering Department;

(xxxi) “right of way” means the width of road or street between two opposite properties

(xxxii) “saleable area” means an area under the residential, commercial and public building plots in a scheme;

(xxxiii) “scheme” means a private housing scheme or a farm housing scheme;

(xxxiv) “Town planner” ‘means a Town Planner registered with the Pakistan Council of Architects and Town Planners; and

(xxxv) “valuation table” means a valuation table notified under the Stamp Act 1899 (II of 1899).

3. Terms not defined.— A word or term used in these rules but not defined shall have the same meaning as in the Ordinance.

CHAPTER II

APPLICATION

4. Submission of an application.– A developer shall, before initiating any planning or development activity of a scheme, submit an application for preliminary planning permission for the scheme to:

(a) the Development Authority in case the scheme falls in a City District; and

(b) in all other cases, to the Tehsil Municipal Administration.”;

5. Attachments with application.— A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall not entertain any application unless accompanied by:-

(a) a certified copy of computerized national identity card of the developer;

(b) complete mailing address of the developer;

(d) a certified copy of certificate of registration of the company or the cooperative society, if applicable;

(e) a location plan of proposed scheme signed by a Town Planner registered with Pakistan Council of Architects and Town Planners; (f) ownership status of proposed land:

(i) self owned; or

(ii) private land not owned by the developer;

(g) financial statement of developer (only if the land is not owned ) including;

(i) bank statement, and

(ii) detail of self owned assets;

(h) if proposed land is not self owned, the financial statement should indicate that enough funds are available to purchase the proposed land; and

(i) a soil investigation report for technical requirements of soil prepared by a consultant engaged by the developer.”

6. Evaluation Criteria for an application.— A concerned officer of a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall satisfy that:

(a) application is complete;

(b) site proposed for scheme fulfills the following requirements:

(i) width of access road is not less than sixty feet in the City Districts and not less than forty feet in other cities;

(ii) site is not prone to flooding;

(iii) area of proposed scheme is not less than hundred kanals;

(iv) site proposed for scheme is not notified by the Government for acquisition for any other public purpose; and

(v) scheme proposal is in conformity with an approved master plan if any.

7. Processing of an application.— (1) In case of a Town Municipal Administration, or a Tehsil Municipal Administration—

(a) a Town Municipal Officer or a Tehsil Municipal Officer shall, within ten days of its submission, forward the application with comments to a District Officer (Spatial Planning);

(b) a District Officer (Spatial Planning) shall within ten days of receipt, submit the case, with its comments, to the District Planning and Design Committee for scrutiny in accordance with these rules; and

(c) after the scrutiny a District Officer (Spatial Planning) shall, within five days, intimate the clearance or observations of the District Planning and Design Committee to a Town Municipal Administration, or a Tehsil Municipal Administration;

(d) a Town Municipal Administration, or a Tehsil Municipal Administration shall, within five days, issue a planning permission or convey observations to a developer:

(2) In case of a development authority:

(a) a Director dealing with processing of private housing schemes shall, within five days forward the case to Water and Sanitation Agency,

(b) Water and Sanitation Agency shall, within ten days, issue a No Objection Certificate or convey observations to the Director dealing with processing of private housing schemes;

(c) a Director dealing with processing of private housing schemes shall, within ten days of receipt of the comments from Water and Sanitation Agency, scrutinize the case in accordance with these rules;

(d) After scrutiny, a Director dealing with processing of private housing schemes shall, within five days, submit the case to the Director General of the Development Authority for permission to proceed for planning of a scheme or otherwise; and

(e) a Director dealing with processing of private housing schemes; shall, within five days, issue a planning permission or convey observations of the Director General to a developer.

8. Preliminary Planning permission.— (1) A preliminary planning permission shall:

(a) be a confirmation that a scheme can be submitted for approval in accordance with these rules;

(b) be valid for six months from the date of issuance;

(c) not be a permission to carry out any construction activities at the proposed site; and (d) not permit marketing of plots or publicity of the scheme.

(2) Only a developer in whose name a planning permission has been issued shall be entitled to submit the scheme.

CHAPTER III

PLAN AND PLANNING STANDARDS

9. Submission of Plan.— (1) A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall entertain an application for sanction of a scheme if submitted within validity period of the preliminary planning permission.

(2) An application shall be accompanied by:

(a) a certified copy of computerized national identity card of a developer;

(b) certified title documents including a registry, intiqal, fard, or any other document;

(d) non encumbrance certificate from the revenue authority;

(e) location plan signed by a Town Planner;

(f) topographic survey extended to a depth of one thousand feet around the scheme area; and

(g) layout plan, super imposed on a khasra plan, with proposed division of scheme into residential and commercial plots, road network, open spaces, graveyard and public buildings prepared and signed by a Town Planner and the owner in accordance with these rules.

(h) certified title documents having hundred percent ownership rights in favour of the developer.”

(3) The requirements under sub-clauses (c), (d), (e) and (f) above shall be submitted in

triplicate.

10. Planning standards for a housing scheme.— (1) A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall ensure that a housing scheme is planned and sanctioned in accordance with the National Reference Manual on Planning and Infrastructure Standards, prepared by Ministry of Housing & Ministry of Environment Government of Pakistan.

(2) Notwithstanding the generality of the sub-rule (1) above, the developer while planning a housing scheme shall adhere to following requirements:

(a) open space or park, seven percent and above;

(b) graveyard, two percent and above;

(d) public buildings from ^{^[1]}two percent to ten percent; and

(e) maximum size of residential plot one thousand square yards;

(f) approach road in five City Districts not less than sixty feet and approach road in other Districts not less than forty feet;

(g) internal roads with minimum ²thirty feet right of way;

(h) accommodation of roads proposed in master plan;

(i) a ten marla plot for solid waste management up to one thousand plots and ten marla plot for every additional one thousand plots;

(j) twenty percent of the plots in a housing scheme shall be reserved /planned forplots upto five marlas for low income group;

(k) Location of a tube well, overhead reservoir, pumping station and disposal station to be provided if required by Water and Sanitation Agency; /

(l) site of grid station to be provided if required by WAPDA, ; And

(m) Green strip under high tension electricity line as per requirements of WAPDA.

11. Planning standards for a farm housing scheme.— (1) A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall ensure that a farm housing scheme is planned and sanctioned in accordance with the National Reference Manual on Planning and Infrastructure Standards.

(2) Notwithstanding the generality of the foregoing (1) above, the developer while planning a farm housing scheme shall adhere to following requirements:

(a) graveyard two percent and above;

(b) commercial area, maximum five percent;

(d) minimum size of residential plot, four kanal;

(e) approach road in City Districts not less than sixty feet and approach road in other cities not less than 40 feet;

(f) internal roads with minimum forty feet right of way;

(g) accommodation of roads proposed in master plan;

(h) a ten marla plot for solid waste management up to one thousand plots and ten marla plot for every additional one thousand plots;

(i) Location of a tube well, overhead reservoir, pumping station and disposal station to be provided if required by WASA and other agencies;

(j) Site of grid station to be provided if required by WAPDA or other agencies

responsible for electricity.; and

(k) Green strip under high tension electricity line as per requirements of WAPDA or other agency responsible for electricity.

12. Technical requirements for the layout plan.— A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall ensure that a layout plan of a scheme is prepared and sanctioned in accordance with the following technical requirements:

(a) scale of scheme plan 1:1200 to 1:2400;

(b) scale of location plan 1: 4800;

(d) chamfering of corner plot by 5x5 feet up to one kanal zone and 10x10 feet for above one kanal zone;

(e) size and dimension of public buildings and open spaces;

(f) right of way of road;

(g) parking area with parking layout;

(h) dimensions of a scheme boundary;

(i) boundary of a mouza or a revenue estate;

(j) number and boundary of each khasra in a mouza; (k) area statement and percentage of—

(i) residential use;

(ii) commercial use;

(iii) open space;

(iv) road;

(v) graveyard;

(vi) public building;

(vii) other uses;

(l) aggregate of various categories of plots with area and, size;

(m) area of existing graveyard, if any, excluding it from area required for a graveyard under these rules;

(n) location of pumping station, if any;

(o) location of overhead tank and tube well if any;

(p) aggregate of various categories of plots to be mortgaged;

(q) signatures of a developer and a Town Planner;

(r) seal of the approving authority;

(s) cardinal sign indicating north;

(t) name of scheme;

(u) names of the mouzas comprising a scheme; and

(v) marking of land to be acquired by a developer, if any.

13. Processing of an application.— A Town Municipal Administration, or a Tehsil Municipal Administration or a Development Authority shall not entertain an incomplete application and inform a developer accordingly within five days of submission of application.

14. Scrutiny of land ownership documents.— (1) If a Town Municipal Administration, or a Tehsil Municipal Administration considers an application complete, then:

(a) a Town Municipal Officer or a Tehsil Municipal Officer shall, within five days of receipt, forward the application, with comments, to a District Officer ( Spatial Planning);

(b) a District Officer (Spatial Planning) shall, within ten days of receipt, submit the case to the ^{^[2]}Additional Collector for scrutiny of the ownership documents;

(c) after the scrutiny a ^{^[3]}Additional Collector shall, within ten days, forward any objections or clearance to a District Officer (Spatial Planning);

(d) a District Officer (Spatial Planning) shall, within five days, forward the objections or clearance to a Town Municipal Officer, or a Tehsil Municipal Officer; and

(e) a Town Municipal Officer, or a Tehsil Municipal Officer shall, within five days, forward the objections to a developer for resubmission:

(2) If a Development Authority considers an application complete, then—

(a) a Director dealing with processing of private housing schemes shall, within five days, forward the application to its revenue staff for scrutiny of ownership documents;

(b) revenue staff of a Development Authority with assistance of a ^{^[4]}Additional Collector shall, within ten days, scrutinize the ownership documents;

(c) after the scrutiny revenue staff of a Development Authority shall forward any objections or clearance to a Director dealing with processing of private housing schemes; and

(d) a Director dealing with processing of private housing schemes shall, within five days, forward the objections to a developer for resubmission.

15. Inviting public objections.— (1) A Town Municipal Officer, a Tehsil Municipal Officer, or a Director dealing with processing of private housing schemes of a Development Authority, after clearance of the ownership documents, shall publish in at least two leading Urdu daily national newspaper and one English daily national newspaper, a Public Notice for inviting objection, in accordance with form A.

(2) Public Notice shall be published at the cost of a developer specifying the following:

(a) location of the scheme;

(b) total area of the scheme;

(d) list of khasra number along revenue estate or mauza;

(e) time limit of fifteen days from the date of publication for filling of objections; and (f) name and address where objections can be filed.

(3) A Town Municipal Officer, a Tehsil Municipal Officer, or a Director dealing with processing of private housing schemes of a Development Authority shall forward the objections, if received, to a developer within five days after the expiry of the time limit given in the public notice, for resubmission.

16. Technical scrutiny of layout plan.— (1) In case the objection is regarding ownership of a portion of land included in this scheme, and both the developer and petitioner have the ownership documents, then the disputed land shall be excluded from the scheme.

(2) In a Town Municipal Administration or a Tehsil Municipal Administration, after the scrutiny of the ownership documents and settlement of public objections:

(a) a Town Municipal Officer or a Tehsil Municipal Officer shall, within ten days, forward the layout with comments to a District Officer (Spatial Planning);

(b) a District Officer (Spatial Planning) shall within ten days of receipt, submit a layout plan with comments to the District Planning and Design Committee for scrutiny in accordance with these rules;

(c) after the scrutiny a District Officer (Spatial Planning) shall, within five days, intimate the clearance or objections of the District Planning and Design Committee to a Town Municipal Administration, or a Tehsil Municipal Administration for further action;

(d) incase of objection a Town Municipal Officer, or a Tehsil Municipal Officer shall, within five days, forward the objections to a developer for resubmission; and

(e) in case of clearance a Town Municipal Officer or a Tehsil Municipal Officer shall, within five days, submit the layout to a Council for approval and intimate the developer within five days of approval of the council.

(3) In a Development Authority, after the scrutiny of the ownership documents and settlement of public objections:

(a) a Director dealing with processing of private housing schemes shall, within ten days,

scrutinize a layout plan in accordance with these rules and forward the

objections, if any, to a developer for resubmission;

(b) in case of clearance a Director dealing with processing of private housing schemes shall, within five days, submit the layout plan to a Director General for

approval: and

(d) a Director dealing with processing of private housing schemes shall intimate the developer within five days of approval of the Director General.

17. Pre-requisites for issuance of sanction of a scheme.— A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall, prior to issuance of sanction for scheme, require a developer to:

(a) submit a transparency of approved layout plan indicating also the plots proposed to be mortgaged;

(b) submit a soft copy of approved layout plan geo-referenced with the coordinate system of survey of Pakistan plan;

(d) deposit the land use conversion fee, if applicable;

(e) submit a transfer deed in accordance with form B for free of cost transfer to a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority:

(i) area reserved for road, open space, park and graveyard, solid waste management; arid

(ii) one percent of scheme area for public buildings, excluding the area of mosque:

(f) submit in the name of a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority:

(i) a mortgage deed, in accordance with form C, twenty percent for housing scheme and ten percent for farm housing scheme of saleable area as security for completion of development works; or

(ii) a performance bond, in accordance with form D and D1, consisting of a performance agreement and a bank guarantee respectively and the amount of bank guarantee shall be equivalent to total cost of development works:

(g) submit a no objection certificate from the Environmental Protection Department.

18. Sanction of scheme.— (1) After fulfillment of the above requirements, a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall issues a formal letter of sanction in accordance with form E.

(2) This letter shall be a formal permission or marketing and sale of the plots in a sanctioned scheme in addition to compliance with marketing requirements under any other law for the time being in force.

(3) If the developer fails to start the development work and sell any of scheme plot in an approved scheme, the development may be allowed, subject to the satisfaction and surety demanded by the competent authority on the payment of prevailing market value of sites reserved for public buildings for Development Authority of Tehsil Municipal Administration, to withdraw the formal letter of sanction by the competent authority of the approved scheme.

(4) The competent authority shall, before approving the withdrawal of the letter of sanction under sub-rule (3) obtain latest complete ownership documents and undertaking of the developer, and issue public notice in two daily newspapers to ensure that no public liability stand against the developer.”

19. Public Notice.— A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall, at the cost of a developer , publish in two Urdu daily national newspapers a public notice in accordance with Form F, giving details of mortgaged plots and salient features of the sanctioned scheme and place the same on the website if available.

CHAPTER IV

MARKETING AND SALE

20. Contents of an advertisement.— (1) A developer shall not advertise sale of plots or housing units in print or electronic media without a prior no objection certification form the competent authority.

(2) The competent authority may grant no objection certification to a development under subrule (1) within fifteen days after fulfillment of conditions prescribed for this purpose.

(3) The advertisement shall contain the following contents:

(a) total area of the scheme with location plan;

(b) aggregate of residential and commercial plots;

(d) period for completion of development works;

(e) name of competent authority and sanction number;

(f) procedure of allotment of plots through balloting or otherwise; and (g) detail of plots to be sold.

(4) An information regarding allotment and sale of plots shall be provided periodically by a developer to the competent authority and update it on his website, if required by the competent authority.”

21. Terms and conditions.— In addition to any other terms and conditions a developer shall include the following in application form for allotment of a property that:

(a) allotted property number shall not be changed without the consent of an allottee;

(b) a developer shall ensure that an allottee becomes member of a resident association and is bound to pay management and maintenance charges on regular basis;

(d) date of handing over possession of the property shall be indicated;

(e) notwithstanding anything in the contract, in case of delayed handing over of possession of the plot / property beyond the stipulated date, the developer shall be liable to pay an amount equivalent to two percent per month of the amount paid by the allottee.

(f) in case the cancellation of property is due to the non-payment of installment of price of property, one opportunity for making required payment shall be given to an allottee;

(g) in case of non-payment of development charges, two opportunities for making required payment shall be given to an allottee; and

(h) in case of cancellation due to default of the purchaser, ten percent price of a property shall be deducted and balance amount to be refunded within six months.

(i) development charges per plot shall be clearly defined in the terms and conditions and shall not be increased without written permission of a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority as the case may be.

“21A. Execution of agreement:- At the time of booking of plots through installments, the developer shall execute an agreement with the purchaser stipulating that on payment of full installment, the developer shall execute the sale deed in favour of the purchaser.”

22. Procedure for disposal of area reserved for two income group.— (1) The plots reserved for low income group shall be allotted on the basis of first-com-first-serve.

(2) The payment of plot shall be recovered in one year through equal monthly installments.

(3) The plot shall not be sold out by the first occupant before expiry of a period of five years.

CHAPTER V

DESIGN AND SPECIFICATIONS

23. Water supply, sewerage and drainage.— (1) A developer shall:

(a) engage services of a qualified public health and structural engineers, who shall be member of the Pakistan Engineering Council for preparation of detailed design and specifications of water supply, sewerage and drainage systems;

(b) ensure that design and specifications are in accordance with law, rules, master plan and guidelines of agency responsible for approval of the same;

(c) ensure that water supply, sewerage and drainage lines are provided on both sides of a road. If provided only along one side of a road then under ground connections for properties on the other side of road shall be provided before road pavement; and

(d) make security of the layout plan of the scheme and after approval of the scheme, submit the design of services, and thereafter the formal approval letter and approved scheme be released.”

(2) A developer shall, in areas where public trunk sewer do not exist, abide by the requirements of Water and Sanitation Agency maintaining a sewerage system and shall ensure disposal of sewage to the satisfaction of Water and Sanitation Agency.

(3) A developer at his cost shall connect sewerage and drainage system of the scheme to a public trunk sewer where-ever available, subject to approval of Water and Sanitation Agency maintaining a sewerage system. After connecting the system to a public trunk sewer, the same may be taken over Water and Sanitation Agency for operation, maintenance and billing.

24. Submission of documents.— A developer shall submit four sets of the following documents of the sanctioned scheme to a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority:

(a) sanctioned layout plan;

(b) location plan;

(d) land use analysis;

(e) soil test report from the approved laboratory;

(f) detailed designs and specifications of water supply, sewerage and drainage system;

(g) number of tube well, their capacity, chamber design, bore hole detail and connection detail with water supply system, including tube well logs (strata chart), details of tube well machinery and installation detail;

(h) numbers of over head tank, capacity, design, structure design and design

calculation detail along with structural stability;

(i) design for ultimate disposal of the sewage; and

(j) location of septic or soakage well, where disposal is not available.

25. Road network.— A developer shall:

(a) engage services of a qualified civil/structural engineer, who shall be registered with the Pakistan Engineering Council for preparation of detailed design and specifications of road network and bridges;

(b) submit, within six months of sanction of a scheme, detailed design and

specifications of a road network, bridge and foot path;

(c) ensure that design and specifications are in accordance with law, rules, master plan and guidelines of agency responsible for approval of the same;

(d) ensure that foot path is provided on both sides of a major road; and

(e) ensure that service road is provided on both sides of a road with more than eighty feet right of way.

26. Submission of documents.— A developer shall submit four sets of the following documents of an approved scheme to a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority:

(a) sanctioned layout plan;

(b) location plan;

(d) soil test report from an approved laboratory;

(e) design and specifications for a road network, bridge and foot path in accordance with law, rules, master plan and guidelines of agency responsible for approval of the same;

(f) geometric design of road network and junction;

(g) land uses analysis;

(h) pavement design;

(i) design of appurtenance arid structure;

(j) road drainage design;

(k) landscape design for a road network; (l) design of street furniture and fixtures; and (m) detail of traffic control devices.

27. Processing of documents.— (1) A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall forward, within a week, the above documents to respective agencies responsible for its approval.

(2) The concerned agency shall, within twenty days, convey objections, if any, to a developer under intimation of a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority.

(3) A developer shall resubmit the documents after removing the objections to the concerned agency.

(4) If satisfied, the concerned agency shall within fifteen days of resubmission, convey the approval of the documents to a developer under intimation of a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority.

(5) A developer shall submit a soft copy of approved documents to the concerned agency. Soft copy of the approved layout plan of infrastructure services of the scheme shall be provided separately.

28. Landscape plan.— A developer shall, within one year of the sanction of a scheme, submit to a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority a landscape plan for parks, open spaces.

29. Solid waste management plan.— A developer shall, within one year of the sanction of a scheme, submit to a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority a solid waste management plan. It shall include a plan showing location of proposed dust bins, storage places and collection and disposal of solid waste system

30. Electricity and street light plan.— (1) A developer shall:

(a) prepare design and specifications of electricity and street light in accordance with law, rules, master plan and guidelines of Local Government responsible for approval of the same;

(aa) A developer shall install/provide energy efficient lights for street/public lighting as may be specified by approving authority/agency/department at the time of approval;

(b) submit, within one year of the sanction of the scheme, these design and specifications to WAPDA responsible for provision of electricity and street light for approval; and

(c) a developer shall ensure that designs are prepared by an electrical engineer registered with the Pakistan Engineering Council and approved by WAPDA responsible for provision of electricity.

(2) WAPDA shall, within twenty days, convey objections, if any, to a developer under intimation of a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority.

(3) A developer shall resubmit the documents after removing the objections to WAPDA.

(4) If satisfied, WAPDA shall within fifteen days after resubmission, after receipt of fee, convey the approval of the documents to a developer under intimation of a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority.

(5) A developer shall submit a soft copy of approved documents to WAPDA.

31. Gas supply charges.— A developer shall, within one year of the sanction of a scheme deposit charges & costs for the provision of gas (if available in the vicinity) in accordance with the requirements of Sui Northern Gas Company/Sui Southern Gas Company under intimation to a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority.

32. Telephone.— A developer shall, within three years of the development of a scheme ensure availability of telephone facilities under intimation to a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority.

33. Under ground services.— (1) A developer shall ensure that utility services such as water supply, sewerage, sui gas and cable lines are laid under ground.

(2) In area where topography does not permit laying of under ground services, exemption may be granted by a plan approving agency under intimation a to Town Municipal Administration, a Tsehsil Municipal Administration or a Development Authority.

CHAPTER VI DEVELOPMENT AND MONITORING

34. Development of a sanctioned scheme.— A developer shall:

( a) execution of all development works within following stipulated time period :

(i) in case of land sub-division; 2 years.

(ii) in case of housing scheme having an area from 100 kanals to 300 kanals: 3 years.

(iii) scheme having an area above 300 kanals: 5 years”;

(b) undertake development works after issuance of approval of design and

specifications by the concerned agencies; and

(c) in case of water supply, sewerage and drainage works, intimate name and address of pipe manufacturing factory to Water and Sanitation Agency, which approved design and specification of water supply, sewerage and drainage.

35. Monitoring of development works in a scheme.— (1) A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall ensure that there is no deviation of the sanctioned scheme plan.

(2) A local government, which approved design and specification shall:

(a) conduct, without prior notice, regular site visits to ensure that development works are in conformity with approved design and specifications;

(b) carry out hydraulic tests for sewer and water supply lines;

(d) complete testing and inspection prior to back filling of trenches and paving road surface;

(e) intimate the developer to rectify any deviations from approved design and

specifications: and

(f) take action against the deviations or violations as per law.

(3) A developer shall—

(a) prior to commencement of development works, inform in writing to an agency which approved design and specifications;

(b) engage services of public health , structural and electrical engineers, who are registered with the Pakistan Engineering Council, to ensure quality control and execution of works in accordance with an approved design and specifications;

(d) engage a qualified consultant engineer duly registered with Pakistan Engineering Council for the supervision and checking quality of development work as per specification and design and if the work is not as per specification or approved design, the same shall be brought by competent authority as per approved

specifications or design at the cost and expense of the developer.” ; and

(4) Testing and inspections carried out by a local government, which approved design and specifications shall be at the cost of a developer.

(5) If a developer fails to develop a scheme within the stipulated period or development works are not in conformity with the approved design and specifications, then:

(a) a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority may take over the development works of the scheme;

(b) a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall execute the development works from the sale proceed of mortgaged plots or encashment of bank guarantee;

(c) in case of differential in cost of development works, a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall recover the shortfall from a developer as arrears of land revenue;

(d) take action against the deviations or violations as per law; and

(e) the competent authority may, on the written request of developer, grant for one time extension irrespective of the time lapsed which shall not be more than two years, and in such a case, the developer shall deposit ten thousand rupees per kanal per annum of the total areas of the scheme.”;

36. Release of mortgaged plots.— A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall release mortgaged plots, in proportion to development works, on obtaining field report from an agency, which approved design and specifications about the satisfactory completion of work as follows:

(a) twenty five percent of mortgaged plots on hundred percent completion of water supply, sewerage and drainage works;

(b) twenty five percent of mortgaged plots on hundred percent completion of road, bridge and footpath works;

(c) twenty five percent of mortgaged plots on hundred percent completion of electricity and streetlight net work or on full payment of charges to WAPDA;

(d) fifteen percent of mortgaged plots on hundred percent payment of gas charge or on full payment of charges to Sui Gas Northern Company / Sui Gas Southern Gas Company; and

(e) ten percent of mortgaged plots on hundred percent completion of horticulture and solid waste management works.

37. Release of bank guarantee.— A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall allow a developer to reduce bank guarantee, in proportion to development works, on obtaining field report from an agency, which approved design and specifications about the satisfactory completion of work as follows:

(a) twenty five percent of bank guarantee on hundred percent completion of water supply, sewerage and drainage works;

(b) twenty five percent of bank guarantee on hundred percent completion of road, bridge and footpath works;

(d) fifteen percent of bank guarantee on hundred percent payment of gas charges; and

(e) ten percent of bank guarantee on hundred percent completion of horticulture and solid waste management works.

CHAPTER VII

FEE

38. Fee.— (1) A developer shall deposit a preliminary planning permission fee along with application at the rate of:

(a) rupees five thousand for scheme having area up to two thousand kanal; and (b) rupees ten thousand for scheme having area above two thousand kanal:

(2) A developer shall deposit a fee for:

(a) sanction of a scheme at the rate of rupees one thousand per kanal;

(b) approval of design and specifications for water supply, sewerage and drainage at the rate of rupees five hundred per kanal;

(c) approval of design and specifications for road, bridge and footpath of a scheme at the rate of rupees five hundred per kanal;

(d) approval of design and specifications for electricity and street light at the rate fixed by WAPDA.

(3) Notwithstanding the sub-rule (1) and sub-rule (2) above the Government may revise the fee from time to time.

39. Fee for conversion of land use.— A developer shall deposit fee for conversion of peri-urban area to scheme use at the rate of one percent of the value of the residential land as per valuation table or one percent of the average sale price of preceding twelve months of residential land in the vicinity, if valuation table is not available.

CHAPTER VIII

LAND SUB-DIVISION

40. Land sub-division.— A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall allow sub-division of:

(a) a plot in an approved scheme; and

(b) a parcel of land which is less than one hundred kanal.

41. Sub-division of a plot in an approved scheme.— (1) A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall, after verification of ownership documents, entertain an application for sub-division of a plot subject to following requirements:

(a) a developer shall be owner of the plot;

(b) a plot shall not be less than one kanal;

(d) a plots of two kanal and above shall only be divided into plots of one kanal or above;

(e) in farm housing scheme a sub-divided plot shall not be less than four kanal;

(f) if a sub-divided plot is not abutting a road, than a sixteen feet wide access road shall be provided within the original plot; and

(g) if more than one sub-divided plots are not abutting a road, than a twenty feet wide access road shall be provided within the original plot.

(2) A developer shall provide internal infrastructure and services for additional plots.

42. Sub-division of a land in area other than an approved scheme.— A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall, after verification of ownership documents, entertain an application for sub-division of land which is less than one hundred kanal subject to following requirements:

(a) ^{^[5]}The land is not prone to flooding;

(b) ^{^[6]}the land is not notified by the Government for acquisition for any public purpose;

(i) surrounded by an existing built up area or an approved housing scheme; and

(ii) separated from the built up area by physical barriers;

(d) ^{^[8]}a developer does not own additional land in continuation of the land proposed for sub-division;

(e) ¹⁰a developer shall provide internal infrastructure and services;

(f^{^[9]}) a^{^[10]} developer shall provide:-

(i) open space or park: seven percent and above;

(ii) commercial area: five percent;

(iii) public buildings: two to ten percent;

(iv) maximum size of residential plot one thousand square yards;

(v) approach road in five City Districts is not less than sixty feet and approach road in other Districts is not less than forty feet;

(vi) internal roads: minimum thirty feet right of way;

(vii) a ten marla plot for solid waste management;

(viii) location of a tube well, overhead reservoir, pumping station and disposal station to be provided if required by Water and Sanitation Agency or Tehsil Municipal Administration;

(ix) green strip under high tension electricity line as per requirements of WAPDA;

(g) ^{^[11]}a developer shall get approval of design and specifications of water supply, sewerage, drainage system, electricity and street light network, road network, solid waste management system in accordance with these rules from the concerned departments;

(h) ^{^[12]}a developer shall submit a transfer deed in accordance with Form B, for free of cost transfer to a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority:

(i) the area reserved for roads, open space, park, solid waste management; and

(ii) one percent of the area under land sub-division for public buildings, excluding the area of mosque; and

(i) ^{^[13]}a developer shall submit in the name of a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority a mortgage deed of twenty percent of the saleable area, in accordance with Form C, as security for completion of development works.”

43. ^{^[14]}Additional requirements for land sub-division.— (1) The provisions of rules 34, 35 and 36 shall apply, as far as possible, to land sub-division of a parcel of land less than one hundred kanal.

(2) The provisions of Chapter VIII shall not apply to the inherited property to be divided among the legal heirs of a deceased for construction of houses for personal use.”

44. Submission of application for sub-division.— A developer shall submit an application for sub-division of a plot or a land to a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority along with the following:

(a) rupees one thousand as a scrutiny fee;

(b) a copy of computerized national identity card of a developer;

(d) non encumbrance certificate issued by a revenue authorities;

(e) sub-division plan, indicating location of existing buildings;

(f) location plan in accordance with these rules;

(g) three sets of sub-division and location plan signed by a developer and a Town Planner; and

(h) No Objection Certificate from the Environmental Protection Department for land forty kanal and above.

45. Approval of sub-division of a plot in an approved scheme.— (1) A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall not entertain an incomplete application and a developer shall be informed accordingly within five days of submission of an application.

(2) A Town Municipal Officer, a Tehsil Municipal Officer or a Director General of a Development Authority shall, after scrutiny and clearance of ownership documents, approve sub-division after deposit of sub-division fee.

(3) A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall determine appropriate sub division fee.

46. Approval of sub-division for less than hundred kanal land.— (1) A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall not entertain an incomplete application and a developer shall be informed accordingly within five days of submission of an application.

(2) If a Town Municipal Administration or a Tehsil Municipal Administration considers an application complete, then for scrutiny of ownership documents:

(a) a Town Municipal Officer or a Tehsil Municipal Officer shall, within five days of receipt, forward the application with comments to a District Officer (Spatial Planning);

(b) a District Officer (Spatial Planning) shall, within five days of receipt, submit the case to the ^{^[15]}Additional Collector for scrutiny of the ownership documents;

(c) after the scrutiny a ^{^[16]}Additional Collector shall, within ten days, forward any objections to a District Officer (Spatial Planning);

(d) a District Officer (Spatial Planning) shall, within five days, forward the objections to a Town Municipal Officer, or a Tehsil Municipal Officer; and

(e) a Town Municipal Officer, or a Tehsil Municipal Officer shall, within five days, forward the objections to a developer for resubmission:

(3) If a Development Authority considers an application complete, then:

(a) a Director dealing with processing of private housing schemes shall, within five days, forward the application to its revenue staff for scrutiny of ownership documents;

(b) revenue staff of a Development Authority with assistance of a ^{^[17]}Additional Collector shall, within ten days, scrutinize the ownership documents;

(c) after the scrutiny revenue staff of a Development Authority shall forward any objections to a Director dealing with processing of private housing schemes; and

(d) a Director dealing with processing of private housing schemes shall, within five days, forward the objections to a developer for resubmission:

(4) In a Town Municipal Administration or a Tehsil Municipal Administration after the scrutiny of the ownership documents:

(a) a Town Officer (Planning and Coordination) or a Tehsil Officer (Planning and Coordination) shall, within ten days, scrutinize a sub-division plan;

(b) incase of objection a Town Officer (Planning and Coordination) or a Tehsil Officer (Planning and Coordination) shall, within five days, forward the objections to a developer for resubmission; and

(c) after the scrutiny a Town Officer (Planning and Coordination) or a Tehsil Officer (Planning and Coordination) shall, within five days, submit a sub-division plan to a Town Nazim or a Tehsil Nazim for approval or passing appropriate orders:

(5) In a Development Authority, after the scrutiny of the ownership documents:

(a) a Director dealing with processing of private housing schemes shall, within ten days, scrutinize a sub-division plan; and forward the objections, if any, to a developer for resubmission;

(b) in case of clearance a Director dealing with processing of private housing schemes shall, within five days, submit a sub-division plan to a Director General; and

(6) A Town Municipal Administration, a Tehsil Municipal Administration or a

Development Authority shall, prior to issuance of approval for sub-division, require a developer to:

(a) submit transparency of technically cleared sub-division plan;

(b) deposit sub-division fee;

(d) submit a transfer deed in the light of Form B for free of cost transfer to a Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority area reserved for road /open space.

(7) A Town Officer (Planning and Coordination) or a Tehsil Officer (Planning and

Coordination) or a Director dealing with processing of private housing schemes of a Development Authority shall, convey the approval of sub-division to a developer on the basis of the technically cleared sub-division plan.

(8) A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall determine appropriate sub division fee.

CHAPTER IX

APPEAL

47. Appeal.— (1) An aggrieved person may, within thirty days of cause of action arising under these rules, file an appeal before the following appellate authority—

(a) Secretary, Local Government and Community Development Department in case of a Town Municipal Administration, a Tehsil Municipal Administration; and

(b) Secretary, Housing Urban Development & Public Health Engineering Department in case of a Development Authority:

(2) The appellate authority shall, within ninety days from the date of filing of the appeal, decide the same whose decision on such appeal shall be final.

(3) An appeal under these rules shall include:

(a) an application signed by the appellant;

(b) a copy of the national identity card of the appellant; and (c) any other document relevant to the appeal.

(4) The appellate authority may pass an interim order during the pendency of an appeal.

CHAPTER X

MISCELLANEOUS

48. Transfer of scheme in revenue record.— (1) A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall, not before twelve months of sanction of scheme and not later then eighteen months of sanction of scheme, shall get the scheme land transferred in the revenue record.

(2) A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall, within nine months of sanction, get land transferred in its name in revenue record as per transfer deed.

49. Management and maintenance of scheme.— (1) After development works are completed and plots are handed over to allotees, plot owners association of a scheme shall be responsible for its management and maintenance.

(2) The plot owners association of scheme shall manage and maintain water supply, sewerage, drainage, street light, electricity, park, road, solid waste and graveyard till such time that these services are taken over by the Government or its agency.

(3) The plot owners association of scheme shall make security arrangements and manage buildings of common use such as mosques and clubs.

(4) The allottees or residents shall contribute proportionately for management and maintenance of the scheme.

“49A. Development of an approved old scheme.– In case of an approved scheme, if the developer is not available then the residents may constitute a committee to be registered with the concerned department for the purposes of approval of revised plan and development of the scheme.”

“50. Modification of scheme. – (1) No modification in a sanctioned scheme shall be made without observing the procedure specified for the sanction of a scheme.

(2) In case of modification of sanctioned scheme, the public amenity sites like open spaces, public buildings shall not be changed in the revised lay out plan but the site reserved for un-utilized graveyard even if transferred in the name of the Development Authority or the Tehsil Municipal Administration may be substituted with some other equal land in the revised lay out plan and the developer shall incur the cost on transfer on of such land.

(3) In case the development period of a sanctioned scheme has already expired and a developer submits the revised plan, it shall not be entertained until the developer is granted extension under clause (c) or rule 35.

(4) In case the developer submits the revised plan within the stipulated time period, only the remaining time period shall be allowed for completion of the development works of the scheme.”.

51. Limits of Peri-Urban Area.— No private housing scheme or land subdivision shall be allowed outside peri-urban area.

52. Plot numbering.— A developer shall fix plot numbers in the scheme as per form G.

53. Guide map.— A developer shall display a guide map at an entrance and other prominent locations in a scheme and board at the corner of road indicating plot numbers and name of roads.

54. Fire hydrant.— A developer shall provide fire hydrant on main water lines in open space, commercial center and at regular interval along a road.

55. Tree plantation.— A developer shall plant trees on both sides of a road and in open spaces.

56. Action against illegal schemes.— A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall take action against illegal housing schemes and against deviations done in sanctioned housing schemes as per law for the time being enforce.

57. Action against violations.— A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall take appropriate action against a developer in case any provision of these rules is violated. The action shall be taken as provided in the law, rules and regulations framed there under.

58. Relaxation of rules.— No provision of these rules shall be relaxed.

59. Repeal and Savings.- (1) The Punjab Private Site Development Schemes (Regulations) Rules, 2005 are hereby repealed.

(2) For purposes of finalization of applications for development of private housing schemes in which scrutiny fee under rule 8(4)(i) of the repealed rules had been deposited in bank account of a local government or a Development Authority, the local government or the Development Authority shall, for the disposal of such applications, apply the planning standards contained in the repealed rules.”

SECRETARY

GOVERNMENT OF THE PUNJAB

LOCAL GOVERNMENT & COMMUNITY DEVELOPMENT

DEPARTMENT

Form- A

Punjab Private Housing Schemes and Land Sub-division Rules

2010

( Rule 15)

PUBLIC NOTICE

( Name, location and address of scheme )

The public is hereby informed that M/s

( Name of developer )

( Address of developer )

Has applied to for sanction of a scheme located in mauza ______________________Tehsil____________________district ______________________ having a total area of ____________ kanal ____________ marla ____________ square feet.

Detail list of khasra numbers alongwith mauza is:

________________________________________________________________

Any person having objection against sanction of the scheme or title of land may, within fifteen days of publication of this notice, submit the same in writing to undersigned. Any objection filed after due date shall not be entertained .This notice shall not be taken a commitment of for sanction of the scheme.

Name of the officer________________

Designation______________________

Address_________________________

Phone No._______________________

Form- B Punjab Private Housing Schemes and Land Sub-division Rules

2010

( Rule 17)

TRANSFER DEED

This TRANSFER DEED made at ___________ on the __________ day of

________________ in year ___________________ by developer ______________ I.D.Card

No/s.______________________ of the Scheme^{^[18]}/land sub-division Located at Mouza

_______________________________________________ hereinafter called the Transferor;

IN FAVOUR OF

Tehsil Municipal Administration / Town Municipal Administration / Development Authority hereinafter called the “Transferee”

WHEREAS the Transferor is absolute owner with possession of land measuring ____________________ kanal __________________ marla __________________ square feet._________________________ bearing khasra Nos. ____________________________ in Mouza __________________________________________________________________

Tehsil / Town District

AND WHEREAS has approved layout plan of scheme^{^[19]}/land subdivision on land of the Transferor, including the area under revenue paths and water courses measuring a total of ____________________ kanal __________________ marla

__________________ square feet. A total area of kanal marla square feet (shown in the plan at annex I) is reserved for public use as detailed below and thereinafter called the property:

sr. public land use kanal marla Sq. Ft

1. Road

2. Park

3. Graveyard

4. public building

5. disposal station and pumping station Total:

Schedule of area under the property is at annex II.

NOW THEREFORE, this deed witnesses as follows:

1. That the transferor hereby warrants that he / she is the absolute owner of the property and no person whatsoever has any charge, encumbrance, lien or mortgage over the property and same is free there from.

2. That in consideration of public welfare the transferor hereby transfers to the Transferee free of charge all his / her rights, interests, easements, appurtenant hereto in the property and to hold the same to the transferee as absolute and lawful owner.

3. That the Transferor further agrees that all times hereinafter, upon request and at expense of the Transferee, to execute or cause to be executed lawful deed and act whatever for better and more perfectly conveying and assuring the property for the Transferee, its heirs, executors, administrators, assignees as shall be reasonably required by the Transferee and placing it in its possession or same according to true interests and meaning of this Deed.

4. That even after execution of this transfer deed the transferor will be responsible for maintenance of area transferred till such time that the same is taken over by an agency responsible for maintenance.

5. That the transferor shall abide by conditions imposed in the Mortgage Deed.

IN WITNESS WHEREOF the Transferor has as here into set his hand on the day and the year first above written.

THE TRANSFEROR

Signed

Name

I.D card No

Address

WITNESS 1	WITNESS 2
Signed	Signed

Name

I.D card

Address

Form-B1

Punjab Private Housing Schemes and Land Sub-division

Rules

2010

Layout plan of scheme

( approved Layout Plan of the scheme showing land transferred through the Transfer Deed )

Form- B 2

Punjab Private Housing Schemes and Land Sub-division

Rules

2010

Schedule of the property

1. Park and open spaces

Plot Number Block Dimension Area

Kanal Marla Sq.ft.

Total Area

2. Public building plots (1% )

Plot Number Block Dimension Area

Kanal Marla Sq.ft

Total Area

3. Graveyard

Plot Number Block Dimension Area

Kanal Marla Sq.ft

Total Area

4. Other plots

Plot Number Block Dimension Area

Kanal Marla Sq.ft

Total Area

5 . Total area under roads

Kanal Marla Sq.feet

Form-C

Punjab Private Housing Schemes and Land Sub-division Rules

2010

( Rule 17)

MORTGAGE DEED

THIS MORTGAGE DEED is made at ___________ on the __________ day of the month of

_______________in the year ___________________ BETWEEN

M/S._______________________________________ N.I.C No__________________________ residing at _______________________________________________________________

(hereinafter referred to as the mortgagor which expression, where the context so admits, shall include heirs, executors, administrators, legal representatives, assigns and successors) of the first part AND the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority of the second part.

WHEREAS the mortgagor applied for sanction of_________________________ Scheme^{^[20]}/land sub-division for an area of _______ kanals _________ marlas __________________ sq.ft. bearing khasra

Nos.__________________________________________________________________________

_____________________________________________________________________________ ___________

_____________________________________________________________________________ ______

Mouzas._______________________________________________________________________ ___

Tehsil_____________________________________District______________________________

The scheme^{^[21]}/land sub-division is approved and the mortgagor has agreed to mortgage twenty percent (ten percent in case of a farm housing scheme) of the saleable area of the said scheme^{^[22]}/land sub-division with Tehsil Municipal Administration, Town Municipal Administration or Development Authority.

NOW this deed witnesses as follows:

1) As a security for provision of development works in the scheme^{^[23]}/land sub-division, the mortgagor hereby grants, assures, demises and mortgages to Tehsil Municipal Administration, Town Municipal Administration or a Development Authority following plots.

Plot Block Dimension Area

Number

Kanal Marla Sq.ft

Total Area

The mortgaged plots are also shown in red color on the scheme^{^[24]}/land sub-division plan at annex C1.

2) The mortgagor shall pay stamp duties, registration charges and other incidental expenses for and in connection with this or any other document to be required inrespect of redemption of this mortgage deed.

3) The mortgagor shall submit and get approved designs of services from the concerned design approving agencies and completes development work within a period of five years after sanction of the scheme^{^[25]}/land sub-division.

4) The mortgagor shall provide paved roads, structure plan roads, sewerage system, drainage system, water supply system, electrification and street lights, horticulture works, solid waste management system, gas etc. within the scheme^{^[26]}/land sub-division area.

5) The mortgagor or the plot owners shall pay the proportionate cost of construction of trunk sewers, sewerage disposal station on proportionate served area basis as and when demanded by the concerned design approving

agency.

6) The Tehsil Municipal Administration, Town Municipal Administration or a Development Authority shall release mortgaged plots, in proportion to development works, on obtaining field report from an agency, which approved design and specifications about the satisfactory completion of work as follows:

a. twenty five percent of mortgaged plots on one hundred percent completion of water supply, sewerage and drainage works;

b. twenty five percent of mortgaged plots on one hundred percent completion of road, bridge and footpath works;

c. twenty five percent of mortgaged plots on one hundred percent completion of electricity and streetlight net work;

d. fifteen percent of mortgaged plots on one hundred percent payment of gas charges; and

e. ten percent of mortgaged plots on one hundred percent completion of horticulture and solid waste management works.

7) On completion of development works, the operation and maintenance of the infrastructure, public and utility services in the scheme^{^[27]}/land sub-division shall be the responsibility of the residents and or the plot owners till such time that the same are taken over by the concerned agencies.

8) The Tehsil Municipal Administration, Town Municipal Administration or a Development Authority shall not be responsible for undertaking development works in the scheme^{^[28]}/land sub-division. If the mortgagor fails to do so and the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority decides to undertake development works, the mortgagor will provide additional funds, if so required, for the development works over and above the amount received from the sale of the mortgaged plots.

9) If at any stage, the land under the scheme^{^[29]}/land sub-division or any part thereof is required by the Tehsil Municipal Administration, Town Municipal Administration ,a Development Authority or the Government for any public purpose, the mortgagor or his successor in interest or any other person claiming any right or interest in the said land shall have no objection to its acquisition.

10) The plots mortgaged to the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority shall be open to inspection at any time by any officer deputed for the purpose.

11) The mortgagor and or all plot owners of the scheme^{^[30]}/land sub-division shall pay to Tehsil Municipal Administration, Town Municipal Administration or a Development Authority the Betterment Fee as and when levied.

12) The mortgagor hereby covenants with the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority and guarantees that he/she:

a. shall from time to time and all times hereafter comply with all rules, regulations and byelaws framed by the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority under the respective laws.

b. has exclusive and absolute ownership of the mortgaged property in which no one else has any claim, concern, right or interest of whatsoever nature.

c. has a legal right, full power, absolute authority to mortgage such property by way of such mortgage deed.

d. has not, prior to the date of these presents, done, made, committed, caused or knowingly done any act under a deed or matter whereby the right to so mortgage has been or may be impaired.

e. hereby declares that the property offered as security for provision of development works is free from all sorts of encumbrances and charges and undertakes that the said property shall not be sold or charged without the prior approval in writing of the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority.

f. shall not put the property in any other charge or otherwise transfer the same or any part thereof in any way and would keep and hold the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority secured harmless and indemnified against all losses and damages caused to be suffered or sustained by the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority as a result of any defect in title or any claim or demand preferred by any one with respect to the property or any part thereof.

g. shall keep the property mortgaged with the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority as security for the provision of development works to the satisfaction of the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority.

13) In case the mortgagor fails to provide the development works as required by the

Tehsil Municipal Administration, Town Municipal Administration or a Development

Authority under the preceding clauses, the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority without any further notice to or concurrence on the part of the mortgagor shall be entitled to: a. take possession of the mortgaged property.

b. sell or dispose off the said property or any part thereof together or in parcel on the account and at the risk of mortgagor either privately or by public auction or by private contract on such terms and conditions as the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority shall think fit and proper, without the bid and intervention of a court of law and without prejudice to the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority’s rights to execute the necessary sale deed, present it for registration and get the same registered and have the necessary mutation of names entered in the Government, revenue records, and on such transfer the property shall vest in the transferee, all rights in or to the property transferred, as if the property had been sold to the transferee by the owner and for the purpose aforesaid or any of them to make agreements, execute assurance and give effectual receipt for discharges for the purchase money and do all other acts and things for completing the sale, which the person or persons exercising powers of sale shall think proper of the aforesaid power shall be deemed to be a power to sell of concur in selling without the intervention of the court under the transfer of property Act-1882.

14) The mortgagor shall abide by the conditions imposed in the letter of sanction of the scheme^{^[31]}/land sub-division.

IN WITNESS WHEREOF the mortgagor as here into sets his hand on the day and the year first above written.

Mortgagor

Signed

Name

I.D card No

Address

WITNESS 1 WITNESS 2

Signed Signed

Name

I.D card I.D card No No

Address

C1 SCHEME PLAN SHOWING MORTAGAGE PLOTS

Area

Plot Number Block Dimension

Kanal Marla Sq.ft.

Total Area

Form-D Punjab Private Housing Schemes and Land Sub-division Rules

2010

( Rule 17)

PERFORMANCE AGREEMENT

THIS PERFORMANCE AGREEMNT is made at ___________ on the ____________day of the month of____________ in the year._____________

BETWEEN

M/S.__________________________________________________________________

I.D.Card.No. ______________________residing at:____________________________ _____________________________________________________________________________ hereinafter referred to as the developer which expression, where the context so admits, shall include heirs, executors, administrators, legal representatives, assigns and successors of the first part AND the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority of the second part.

WHEREAS the developer applied for sanction of_________________________ scheme for an area of____________ kanals_________ marlas__________ sq.ft.

Bearing khasra Nos.________________________________________________ ______________________________________________________________________ in

mouzas.________________________________________________________ ______________________________________________________________________

Tehsil__________ District___________ and the scheme is approved. The developer has agreed to submit a bank guarantee equal to the total cost of the provision of development works of the said scheme to the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority.

NOW this Agreement witnesses as follows:

1. That as a security for provision of development works of the scheme, the developer hereby submits to Tehsil Municipal Administration, Town Municipal Administration or a Development Authority a Bank Guarantee for Rs. ________, equal to total cost of provision of development works of the scheme.

2. The developer shall pay all charges for stamp duties, registration charges and other incidental expenses for and in connection with the Performance Agreement and the Bank Guarantee.

3. That the Developer shall get approved designs of services from concerned design approving agencies and will complete development works within a period of five years after sanction of the scheme.

4. The developer shall provide paved roads, structure plan roads, sewerage, drainage system, water supply system, electrification and street lights, horticulture works, solid waste management system, gas, etc. within the said scheme area.

5. The developer or the plot owners shall pay the proportionate cost of construction of trunk sewers, sewerage disposal station on proportionate served area basis as and when demanded by the concerned design approving agency.

6. A Town Municipal Administration, a Tehsil Municipal Administration or a Development Authority shall allow the developer to reduce bank guarantee, in proportion to development works, on obtaining field report from an agency, which approved design and specifications about the satisfactory completion of work as follows:

(a) twenty five percent of bank guarantee on one hundred percent completion of water supply, sewerage and drainage works;

(b) twenty five percent of bank guarantee on one hundred percent completion of road, bridge and footpath works;

(d) fifteen percent of bank guarantee on one hundred percent payment of gas charges; and

(e) ten percent of bank guarantee on one hundred percent completion of horticulture and solid waste management works.

7. On completion of development works in the scheme, the operation and maintenance of the infrastructure, public and utility services in the scheme shall be the responsibility of the residents and or the plot owners till such time that the same are taken over by the concerned agencies.

8. The Tehsil Municipal Administration ,Town Municipal Administration or a Development Authority shall not be responsible for undertaking development works in the scheme if the developer fails to do so and the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority decides to undertake development works the developer shall provide additional funds, if required so, for the development works over and above the amount received from the encashment of the Bank Guarantee, due to increase in cost of the development works.

9. If at any stage, the land under the scheme or any part thereof is required by the

Tehsil Municipal Administration, Town Municipal Administration, a Development Authority or Government for any public purpose, the developer or his successor in interest or any other person claiming any right or interest in the said land shall have no objection to its acquisition.

10. The developer and or plot owners shall pay to the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority the Betterment Fee as and when levied.

11. The developer hereby covenants with the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority and guarantees to comply with all rules, regulations and byelaws framed by the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority under the respective laws.

12. That the developer shall abide by the conditions imposed in the Letter of sanction of the scheme.

13. The Tehsil Municipal Administration, Town Municipal Administration or a Development Authority may extend the completion date by mutual agreement keeping in view unforeseen circumstances and the Performance Agreement shall be amended accordingly. The validity of the Bank Guarantee shall also be extended and total amount shall be enhanced if cost of development works is expected to increase due to extension in completion date.

14. If the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority feels that the development works are expected not to be completed in the remaining time period, it may ask the developer, fifteen days before its expiry, to immediately extend the Bank Guarantee. If the developer does not extend the same, a week prior to its expiry, then the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority shall encash it before expiry.

15. In case the developer fails to provide the approved development works as required under the preceding clauses, the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority without any further notice to or concurrence on the part of the developer shall be entitled to;

a. encash the Bank Guarantee.;

b. spend the amount encashed on the provision of development works in the scheme through contracts and on such terms and conditions as the Tehsil Municipal Administration ,Town Municipal Administration or a Development Authority thinks fit and proper, without the bid and intervention of a court of law and without prejudice to the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority’s rights to do all other acts and things for completing the development works.

16. Upon written confirmation by all concerned agencies of the satisfactory completion of all the works as per Performance Agreement, the Bank Guarantee shall be released immediately.

IN WITNESS WHEREOF the developer as here into sets his hand on the day and the year first above written.

Developer

Signed

Name

I.D card No

Address

WITNESS 1 WITNESS 2

Signed Signed

Name

I.D card No I.D card No

Address

D1 Punjab Private Housing Schemes and Land Sub-division Rules

2010

( Rule 17)

BANK GUARANTEE

INSTRUCTIONS FOR SUBMISSIONOF BANK GUARANTEE

1. Bank Guarantee is to be executed on Rs, 1000, non judicial stamp papers.

2. Bank Guarantee must accompany a covering letter from the issuing bank.

3. Two additional copies of the Bank Guarantee shall be submitted and each page of the bank guarantee shall be stamped and signed.

4. The Bank Guarantee shall be as per given specimen.

( SPECIMEN )

BANK GUARANTEE

BANKS GUARANTEE NO_________ DATED___________________________

AMOUNT______________________

EXPIRARY DATE_______________

Whereas a Performance Agreement dated ______________has been executed between (Name of the Tehsil Municipal Administration, Town Municipal Administration or a Development Authority) and M/s. (Name of the Developer of the Scheme) for the development of the (Name of the scheme) Scheme as per terms and conditions contained in the said Performance Agreement.

AND WHEREAS you have required the Developer to furnish, a Bank Guarantee equivalent to the amount Rs. ( in figures) Rupees (in words).

1. NOW THEREFORE in consideration of the aforesaid we (Name of the Bank) do hereby bind ourselves, unconditionally and irrevocably, and guarantee to pay you the said amount without objection or reservation or any reference to the Developer, within three days of the receipt of the written demand notice, before the expiry of this Bank Guarantee.

2. This Guarantee shall continue to be in full force and operative and binding on us, until all the requirements of the Performance Agreement have been complied with.

3. Any such demand made by you on default by the Developer, shall deemed to be conclusive by the mere fact of placing a demand. We shall be bound to encash this Bank Guarantee on demand.

4. Our obligation under this Guarantee shall not be discharged or affected by:

a. Any time or any indulgence given by you to the Developer in respect of any obligation of the Developer under the Performance Agreement.

b. Any variation of any provision of the Performance Agreement.

c. Any dissolution, winding up or corporate reorganization of the Developer.

d. Any transfer or extinguishing of any of the liability of the Developer by any law, regulation, decree, judgment order or similar instrument.

5. Our liability under the Bank Guarantee shall, in any case, not exceed the sum of Rs. ( in figures) Rupees (in words).

6. We will be released and discharged of our liability, if no claim is lodged with us on or before (Expiry date of the Bank Guarantee).

7. This Bank Guarantee shall constitute an irrevocable arrangement binding on us and our successor in interest, and shall inure to the benefit of your successor in-interest, assigns under Agreement.

For and on behalf of the bank:

Seal and signatures of the authorized person

Designation

Name of the bank

WITNESS 1 WITNESS 2

Signed Signed

Name

I.D card No I.D card No

Address

COVERING LETTER

BANKS GUARANTEE NO___________

DATED___________________________

AMOUNT_________________________

EXPIRARY DATE__________________

To,

_____

Dear Sir,

As per request of M/s(name of the Developer) we hereby enclose Bank Guarantee No____________ dated __________in your favour, the sum of Rs. (in figures) and (in words) on account of M/s(name of the Developer)

We, hereby undertake to make an unconditional payment of Rs. (in figures) and (in words) to you on your first written demand and without recourse to the Developer as per the provisions of Bank Guarantee,

This Bank Guarantee shall remain valid and in full force till the expiry date, after which no claim will be entertained.

Any claim arising t of this Guarantee must be lodged in writing within the validity period of Bank Guarantee, certifying that the Developer has failed to meet the requirements under Performance Agreement.

For and on behalf of the bank:

Seal and signatures of the authorized person

Designation

Form-E Punjab Private Housing Schemes and Land Sub-division Rules

2010 ( Rule 18) From :

________________

To:

________________

SUBJECT: SANCTION OF SCHEME (name and location of scheme)

The scheme plan submitted by you for an area measuring

______________kanals________________ marlas_______________sq.ft in

Mouza/s_______________________________________________ in Tehsil_______________________ and District_____________ has been sanctioned by (Name of Tehsil Municipal Administration, Town Municipal Administration or Development Authority)

This sanction of the scheme is subject to the following conditions:

1. No change in land use of plots will be allowed at later stage in violation of any prevailing Laws for the time being enforce

2. The approval of designs of services such as water supply, sewerage and drainage systems and of roads shall be obtained from the agencies responsible for its approval

3. The approval of design of electrification and street lights shall be obtained from WAPDA or other agency designated for it.

4. The development works in the scheme shall be completed in accordance with the approved designs and specifications.

5. All development works shall be completed within a period of five years from the date of issue of this letter.

6. Construction of buildings shall be undertaken after approval of building plans in accordance with prevailing Building and Zoning Regulations/Bye-Laws.

7. Proportionate cost for the provision of trunk services on proportionate area basis shall be paid by the plot owners as and when demanded by the concerned agency.

8. Provision of horticulture and landscaping of the scheme area will be done as per approved plans.

9. The operation and maintenance of the schemes after completion of development works shall be responsibility of the plot owners association.

10. In case of any litigation or objection regarding the land ownership, you will be responsible for the same and (Name of Tehsil Municipal Administration, Town Municipal Administration or Development Authority) shall not be a party in this issue. You will be responsible to settle any dispute about ownership of land if arises at any stage.

11. The plot owners shall pay any betterment charges as and when levied by the concerned agency.

12. In case of any complaint from the plot owners you or plot owners association shall be responsible to settle the issue.

13. You will display a copy of approved scheme plan, a copy of sanction letter and a list of mortgaged plots in your office.

14. You will abide by the terms and conditions of the Transfer Deed and Mortgage Deed/Performance Agreement and Bank Guarantee.

15. No revision in layout plan and design specification etc. to be done without the approval of concerned agency.

16. You will make arrangements to hand over the possession of the areas to (Name of Tehsil Municipal Administration, Town Municipal Administration or Development Authority) as per Transfer Deed.

17. You shall get the approved scheme transferred in revenue record within six months after the sanction of the scheme

18. The advertisement and publicity material shall include:

i. Total area and location; ii. Total number of residential and commercial plots of various sizes; iii. detail of mortgaged plots. iv. Period for completion of development works. v. Method of allocation of plot numbers.

21. Sale or commitment of plots over and above the total number of plots provided in the approved scheme is not allowed.

22. Sale or commitment of mortgaged plots is not allowed before their redemption.

23. Full contents of this letter shall be given in the publicity brochure prepared for the sale of plots.

24. You will take up the case regarding the proposed acquisition of land if any with the concerned authority; The Plan approving authority has nothing to do with it.

25. You shall include all the general terms and conditions under these Rules in your application forms.

Name of the officer________________

Designation______________________

Address_________________________

________________________________

Form-F Punjab Private Housing Schemes and Land Sub-division Rules

2010

( Rule 19)

PUBLIC NOTICE

( Name and location of the scheme )

The public is hereby informed through this notice that M/s (Name and Address of the developer) has applied to (Name of Tehsil Municipal Administration, Town Municipal Administration or Development Authority) for sanction of the scheme named (name of scheme) located in mauzas(name of mauzas) in tehsil(name of tehsil) in district(name of district), having a total area of ____________ kanals___________ marlas _____________sq.ft.

(Name of approving agency) has sanctioned this scheme.

Detail of various categories of plots provided in the scheme is as follows:

Residential Size of Plots No. of Plots

Commercial

Others

The public is hereby informed through this notice that the following plots in the scheme have been mortgaged with the (name of approving agency) as security towards provision of development works (provision of roads, water supply sewerage and drainage system, street light and electricity net work, gas facilities and horticulture works). It is the responsibility of the developer of the scheme to provide and complete the development work. The developer cannot sell or transfer these plots until these are redeemed after due completion of the development works. List of mortgaged is as follows;

Plot Block Dimension Area Use

Number

Kanal Marla Sq.ft.

Total Area

Public is informed through this notice not to enter into any transaction, sale or purchase of the mortgaged plots till they are redeemed.

Name of the officer________________

Designation______________________

Address_________________________

Phone No._______________________

Form-G

Punjab Private Housing Schemes and Land Sub-division Rules

2010

( Rule 51)

NUMBERING OF PLOTS AND ROADS

1 . NAMING THE BLOCKS

i. The scheme may be divided into Blocks keeping in view its area.

ii. Efforts shall be made to ensure that each Block is bounded in such a way that total numbers of plots in the Block do not exceed 500 or so. iii. Boundaries of each Block shall be well defined with a road or prominent physical feature

iv. These Blocks shall be named or given alphabetical numbers.

2. NAMING THE ROADS

Each road shall be given a name, numerical or alphabetical number for identification

3. NUMBERING OF PLOTS

A particular plot in a street shall be given a unique/specific number. The intention is to make it easier to locate it. There are different systems being followed for numbering of plots, same are summarized below.

Option 1

Odd numbers on the left side, as viewed from the datum point at the start of the road, and even numbers on the right side. Along long roads numbers will typically ascend until the road crosses a junction or reaches the boundary of the next Block.

Option 2

To proceed sequentially along one side of the road and then back down the other, it is a combination of clockwise and anti clockwise system, depending on the layout plan.

Option 3

First roads are numbered. Then plots are numbered along both sides of the road sequentially or on odd/even system basis. In this case the road numbers vary but the plot numbers in each road start from one.

Option 4

Plots which surround a square are usually numbered consecutively clockwise.

Form-H Punjab Private Housing Schemes and Land Sub-division Rules

2010

CHECK LIST FOR SANCTION OF A SCHEME

STATUS

A-DOCUMENTS REQUIRED
1.	Certified copy of national identity card of developer;
	YES	NO
2.	Certified title documents including a registry, intiqal, fard, or any other document;
	YES	NO
3.	Khasra plan or aks-e-shajra certified by a tehsildar
	(revenue; YES	NO
4.	Topographic survey plan extended to a depth of one thousand feet around the scheme area;
	YES	NO
5.	YES Location plan signed by a town planner;	NO
6.	YES Layout plan signed by a town planner and developer;	NO
7.	Requirements under (c), (d), (e) and (f) above are submitted in triplicate ;
	YES	NO
8.	Details of development works along with time schedule;
	YES	NO
9.	Details of land proposed to be acquired, if any, the land proposed to be acquired does not exceed twenty percent of the total area owned by the developer in the
	scheme; and YES	NO
YES 10. Scrutiny fee paid		NO
B- PRELIMINARY CHECKING STATUS 1. application is complete YES NO

2. Planning permission was issued to the developer;

YES NO 3. Is the scheme submitted within the validity period of
the Preliminary Planning Permission;	YES NO
C-SCRUTINY OF OWNERSHIP DOCUMENTS	STATUS
1. Ownership documents cleared by the revenue office.	YES NO
2. Public notice given for inviting objections.	NO YES
3. Objections received, if any, settled by the developer.	YES NO
D- SCRUTINY OF SCHEME PLAN	STATUS
1. scale of scheme plan is correct	YES	NO
2. scale of location plan is correct	YES	NO
3. size and dimensions of each plot is given	YES	NO
4. chamfering of corner plot by 5x5 feet up.to one kanal YES and 10x10 feet for two kanal and above is done.		NO
5. size and dimension of public building and open space YES is given;		NO
6. right of way of road is written; YES		NO
7. parking area with parking pattern is indicated; YES		NO
8. dimensions of boundary of scheme is written YES		NO
9. boundary of a mouza or a revenue estate and khasras YES is superimposed on the layout plan;		NO
10.number and boundary of each khasra in a mouza is YES		NO

given;

11.area and land use percentage of following is given

(viii) residential use;

(ix) commercial use;

(x) open space;

(xi) road;

(xii) graveyard;

(xiii) public building;

(xiv) other uses;

1. aggregate of various categories of plots with area and,

size is given; YES 2. area of existing graveyard, if any, excluding it from	NO
area required for a graveyard is given separately YES	NO
3. location of pumping station, if any;is shown YES 4. location of overhead tank and tube well is shown;	NO
YES 5. list of various categories of plots to be mortgaged is given and hetched;	NO
YES 6. signatures of the developer and a town planner	NO
YES	NO
7. seal of the approving authority is given YES	NO
8. cardinal sign indicating north is shown YES	NO
9. name of scheme if any is given; YES	NO
10.names of the mouzas comprising a scheme are given; YES and	NO
E-PLANNING STANDARDS COMPLIED WITH STATUS ( HOUSING SCHEME ) NO 1. Open space or park not less than seven percent YES NO 2. Commercial area is five percent YES NO 3. Graveyard not less than two percent YES 4. Public Buildings from five to ten percent; YES NO 5. Area of residential plot not more than one thousand square yards; YES NO 6. Internal roads not less forty feet right of way; YES NO

7. Roads proposed in peri-urban structure plan and master plan are accommodated;

YES NO h. A ten marla plot for storage of solid waste provided per thousand plots YES NO F-PLANNING STANDARDS COMPLIED WITH STATUS ( FARM HOUSING SCHEME ) 1. Graveyard not less than two percent YES NO 2. Commercial area is five percent YES NO 3. Open space or park, Public Buildings, public utility sites not less than seven percent, YES NO 4. Area of residential plot not less than four kanal YES NO 5. Internal roads not less forty feet right of way YES NO 6. Roads proposed in peri-urban structure plan and YES NO master plan are accommodated; 7. A ten marla plot for storage of solid waste provided per YES NO
thousand plots
G-PRE-REQUESTES FOR ISSUANCE OF SANCTION OF SCHEME	STATUS
1. Approved by the competent authority	YES	NO
2. Submitted a transparency of approved layout plan;	YES	NO
3. Submitted a soft copy of approved layout plan;	YES	NO
4. Deposited scheme approval fee;	YES	NO
5. Deposited the land use conversion fee, if applicable;	YES	NO
6. Submitted the Transfer Deed	YES	NO
7. Submitted the Mortgage Deed or a Performance YES Agreement with a Bank Guarantee 8. Submitted a No Objection Certificate from the		NO
Environmental Protection Department. YES		NO

Issue letter of sanction in accordance with form E

Issue public notice as per rule 19 in accordance with form F

H- FOLLOW UP ACTIONS STATUS
1. Advertisements are as per Rule 20 YES 2. Terms and conditions as per Rule 21 included in the	NO
allotment letter YES 3. Designs for Water Supply & Sewerage System	NO
Submitted YES 4. Designs for Water Supply & Sewerage System	NO
approved YES	NO
5. Designs for Road network Submitted YES	NO
6. Designs for Road network approved YES	NO
7. Landscape Design Submitted YES	NO
8. Solid Waste Management Plan Submitted YES	NO
9. Designs for electricity & Street Light Submitted YES	NO
10.Designs for electricity & Street Light approved YES 11.Gas Supply Charges Submitted to the Concerned	NO
Department YES 12. The Local Govt/development authority has transferred	NO
the scheme in the revenue record YES 13. The Local Govt/development authority. has transferred	NO
the Transfer Deed in the revenue record YES	NO
14.Scheme is being developed as per YES Sanctioned layout plan	NO
If not ,action is being taken as per law YES 15.Infrastructure and utility services are being laid as per	NO
approved designs and specifications YES	NO
If not ,action is being taken as per law YES	NO

16.twenty five percent of mortgaged plots on hundred percent completion of water supply, sewerage and

drainage works ^YES 17.twenty five percent of mortgaged plots on hundred percent completion of road, bridge and footpath works;	NO
YES 18.twenty five percent of mortgaged plots on hundred percent completion of electricity and streetlight net	NO
work; YES 19.fifteen percent of mortgaged plots on hundred percent payment of gas charges; and	NO
YES 20.ten percent of mortgaged plots on hundred percent	NO
completion of horticulture and solid waste management works ^YES	NO
21.Developer has installed Guide Maps In the Scheme. YES 22.Welfare Society for Management & Maintenance of the	NO
Scheme is functioning YES	NO

GOVERNMENT OF THE PUNJAB

LOCAL GOVT. & COMMUNITY DEVELOPMENT

DEPARTMENT

Dated Lahore, the November, 2013

NOTIFICATION

No.SOR(LG)38-2/2004. In exercise of powers conferred under section 191 of the Punjab Local

Government Ordinance, 2001 (Xlll of 2001), Governor of the Punjab is pleased to direct that in the Punjab Private Housing Schemes and Land Sub-Division Rules, 2010, the following amendments shall be made.

AMENDMENTS

In the said rules;

1. For rule 4, the following shall be substituted:

“4. Submission of an application.– A developer shall, before imitating any planning or development activity of a scheme, submit an application for preliminary planning permission for the scheme to:

(d) in all other cases, to the Tehsil Municipal Administration.”;

2. In rule 5, in clause (h), for full stop at the end, a semi-colon and the word “;and” shall be substituted and, thereafter, the following clause (i) shall be inserted:

“(i) a soil investigation report for technical requirements of soil prepared by a consultant engaged by the developer.”

3. In rule 9, in sub-rule (2), after clause (g), the following clause (h) shall be inserted:

“(h) certified title documents having hundred percent ownership rights in favour of the developer.”

4. In rule 18, after sub-rule (2), the following sub-rule (3) and (4) shall be inserted:

“(3) If the developer fails to start the development work and sell any of scheme plot in an approved scheme, the development may be allowed, subject to the satisfaction and surety demanded by the competent authority on the payment of prevailing market value of sites reserved for public buildings for Development Authority of Tehsil Municipal Administration, to withdraw the formal letter of sanction by the competent authority of the approved scheme.

5. For rule 20, the following shall be substituted:

“20. Contents of an advertisement.— (1) A developer shall not advertise sale of plots or housing units in print or electronic media without a prior no objection certification form the competent authority.

(i) The competent authority may grant no objection certification to a development under sub-rule (1) within fifteen days after fulfillment of conditions prescribed for this purpose.

(ii) The advertisement shall contain the following contents:

(h) total area of the scheme with location plan;

(i) aggregate of residential and commercial plots;

(j) detail of mortgaged plots;

(k) period for completion of development works;

(l) name of competent authority and sanction number;

(m) procedure of allotment of plots through balloting or otherwise; and (n) detail of plots to be sold.

6. After rule 21, the following rule 21A shall be inserted:

7. In rule 23, in sub-rule (1), for clause (d), the following shall be substituted:

“(d) make security of the layout plan of the scheme and after approval of the scheme, submit the design of services, and thereafter the formal approval letter and approved scheme be released.”

8. In rule 34, clause (a), the following shall be substituted:

“(a) execution of all development works within following stipulated time period :

(i) in case of land sub-division; 2 years.

(ii) in case of housing scheme having an area from 100 kanals to 300 kanals: 3 years.

(iii) scheme having an area above 300 kanals: 5 years”;

9. In rule 35:

(i) In sub-rule (3), after clause (b), the word “and” shall be omitted and in clause (c), the full stop at the end shall be replaced by a semicolon and the expression”; and” and thereafter the following clause (d) shall be inserted:

“(d) engage a qualified consultant engineer duly registered with Pakistan Engineering Council for the supervision and checking quality of development work as per specification and design and if the work is not as per specification or approved design, the same shall be brought by competent authority as per approved specifications or design at the cost and expense of the developer.” ; and (ii) In sub-rule (5):

(a) for clause (e), the following shall be substituted:

“(e) the competent authority may, on the written request of developer, grant for one time extension irrespective of the time lapsed which shall not be more than two years, and in such a case, the developer shall deposit ten thousand rupees per kanal per annum of the total areas of the scheme.”;

10. After rule 49, the following rule 49A shall be inserted:

11. For rule 50, the following shall be substituted:

“50. Modification of scheme. – (1) No modification in a sanctioned scheme shall be made without observing the procedure specified for the sanction of a scheme.

(4) In case the developer submits the revised plan within the stipulated time period, only the remaining time period shall be allowed for completion of the development works of the scheme.”

JAWWAD RAFIQUE MALIK

Secretary, LG&CD Department

( Tabish Mehmood Butt )

Section Officer (Regulations)

[1] Substituted vide Notification dated 3-8-2011 ² ibid

[2] Substituted vide notification dated 15.08.2012

[3] Substituted vide notification dated 15.08.2012

[4] ibid

[5] Substituted vide notification dated 15.08.2012

[6] ibid

[7] ibid

[8] ibid

[9] Substituted vide notification dated 15.08.2012

[10] ibid

[11] ibid

[12] ibid

[13] ibid

[14] ibid

[15] Substituted vide notification dated 15.08.2012

[16] ibid

[17] Substituted vide notification dated 15.08.2012

[18] Substituted vide notification dated 15.08.2012

[19] ibid

[20] Substituted vide notification dated 15.08.2012

[21] ibid

[22] ibid

[23] ibid

[24] Substituted vide notification dated 15.08.2012

[25] ibid

[26] ibid

[27] ibid

[28] Substituted vide notification dated 15.08.2012

[29] ibid

[30] ibid

[31] Substituted vide notification dated 15.08.2012

Pak Law

Tuesday, 31 March 2015

PUNJAB PRIVATE HOUSING SCHEMES AND LAND SUB- DIVISION RULES 2010

PUBLIC NOTICE

TRANSFER DEED

Layout plan of scheme

Schedule of the property

MORTGAGE DEED

PERFORMANCE AGREEMENT

BANK GUARANTEE

PUBLIC NOTICE

NUMBERING OF PLOTS AND ROADS

No comments:

Post a Comment